研究生: |
王則凱 Tse-Kai Wang |
---|---|
論文名稱: |
公共工程共同遲延與管理費補償計算模式之研究 Compensation of Project Overhead Damages for Concurrent Delay in Public Construction |
指導教授: |
李得璋
The-Chang Lee |
口試委員: |
王慶煌
none 呂守陞 Sou-Sen Leu |
學位類別: |
碩士 Master |
系所名稱: |
工程學院 - 營建工程系 Department of Civil and Construction Engineering |
論文出版年: | 2013 |
畢業學年度: | 101 |
語文別: | 中文 |
論文頁數: | 113 |
中文關鍵詞: | 公共工程 、工期展延 、共同遲延 、工程管理費補償 |
外文關鍵詞: | Construction Claim, Concurrent Delays, Allocable Overhead |
相關次數: | 點閱:551 下載:12 |
分享至: |
查詢本校圖書館目錄 查詢臺灣博碩士論文知識加值系統 勘誤回報 |
本研究旨在針對因工期展延與共同遲延所衍生的工程管理費補償問題進行探討,確認國內承包商在工程展延與共同遲延方面有關管理費補償請求之現況與爭議重點 。並評析現行工期展延計算分析方法關於共同遲延之責任分配方式,從而研訂可補償項目,建立管理費之補償計算基準及相關處理模式,以供工程主辦機關辦理管理費補償之參考。
本研究首先透過相關文獻蒐集整理,探討國內外共同遲延之重點課題,並評析現行常用遲延分析技術於共同遲延之適用性。蒐集整理國內公共工程有關工程展延實務上調解、仲裁判斷或法院判決之共同遲延案例,使用時間影響分析法、視窗分析法、快照分析法、同期時段分析法及總浮時管理分析法等5種方法進行分析,結果顯示不同遲延分析技術於不同共同遲延情形分析結果存有差異性。並進一步利用模擬分析探討差異之情形,計算出共同遲延管理費補償金額修正係數。本研究乃參考英國營建法學會(SCL)之工程遲延處理準則,就共同遲延補償天數之修正及管理費補償費用之調整,建構涉及共同遲延之工期展延管理費補償計算模式。
It is generally recognized that construction delays is critical in public construction projects. Contractors may claim incurred costs for excusable and compensable delays. And it often leads to contract disputes due to the lack of effective settlement approaches. The presence of concurrent delay adds to the complexity of delay analysis as it has become the most common defense raised by owners faced with a contractor's claim for delay damages. Therefore, it is imperative to develop methods for calculating overhead claims for damages due to concurrent delay. Whatsoever, apportioning responsibilities of concurrent delay between the two parties is extremely difficult, due to the complicated nature both in the Construction programme as well as the circumstances under which methodology should be applied. The main objective of this study is thus aimed to assist in the quick and efficient calculation of the appropriate compensation due a contractor for concurrent delay.
In this study, key issues and the major problems encountered in the calculation of damage of compensable delay of public construction were investigated first and guidances set up in the SCL Delay and Disruption Protocol (DDP) were examined. In addition, the existing methodologies for analysing concurrent delay claims with a view to identifying the problems associated with their current usage towards apportionment were explored. Then, seven case studies were conducted to evaluate the differences of calculating overhead claims for damages due to concurrent delay using various delay analysis techniques such as Time Impact Analysis,Snapshot Analysis and Window Analysis etc. Base on the result, guidelines of appropriate compensation for concurrent delays were established consequently.
1.高宗正、黃馨慧、藍秉強、蕭偉松,「因工期展延所生費用之求償問題」,工程法律系列論壇(四),民國97年。
2.高志魁,「時程遲延分析技術之建立與實證研究」,中華大學科技管理研究所博士論文,民國98年。
3.李惠貞,「展延工期增加費用相關問題-兼論美國法之展期索賠」,工程法律實務研析(二),元照出版,147~184 頁,民國95 年。
4.王伯儉,「延長工期之費用補償」,營造天下,54~59 頁,第41 期,民國88 年。
5.王伯儉,「論工程管理費之請求」,營造天下,39~44 頁,第32 期,民國87 年。
6.洪妙晶,「工期遲延請求展延工期及損害賠償之研究」,營造天下,17~21 頁,民國90 年。
7.粱鑑、陸繼雄,「國際工程施工索賠」,淑馨出版社,民國88年。
8.李宗德,「大型公共工程合約中衍生性損害賠償之適用及其應有之限制」,營建管理季刊,第25卷,52-60頁,民國84年。
9.鄭明龍,「營建工程遲延分析」,國立高雄第一科技大學營建工程系碩士論文,民國92年。
10.郭麗華,「工程間接費用索賠計算方法之比較」,國立成功大學土木工程研究所碩士論文,民國94年。
11.張嘉琪,「共同遲延責任分配之系統化分析方法」,國立中央大學營建管理所碩士論文,民國96年。
12.林聰意,「營建專案共同遲延責任分配之研究」,國立高雄第一科技大學營建工程系碩士論文,民國97年。
13.李怡瑤,「時程延遲分析技術改進與實作」,中華大學營建管理研究所碩士論文,民國96年。
14.阮齡瑩,「工程遲延分析法之探討」,國立高雄第一科技大學營建工程系碩士論文,民國98年。
15.曾智威,「公共工程工期展延與管理費補償計算模式之研究」,國立台灣科技大學營建工程系碩士論文,民國100年。
16.日本國土交通省土木工事積算基準,第3章現場管理費率の補正,官房技術調查室監修,平成20年度版。
17.工程項目管理,
18.Society of Construction Law, “Delay and Disruption Protocol”, Printmost (Southern) Ltd, England, 2002.
19.Trauner, T. J., “Construction Delays: Understanding Them Clearly, Analyzing Them Correctly”, Butterworth-Heinemann, 2009.
20.Keane, P. J. and Caletka, A. F., “Delay Analysis in Construction Contracts”, Blackwell Publishing Ltd, 2008.
21.Al-Gahtani, K. S., “A Comprehensive Construction Delay Analysis Technique Enhanced with a Float Ownership Concept”, Ph. D. Dissertation, University of New York at Buffalo, 2006.
22.Holland, N. and Hobson, D., “Indirect Cost Categorization and Allocation by Construction Contractors”, Journal of Architectural Engineering, Vol.5, No.2, 1999.
23.Schwartzkopf, W., McNamara, J. J. and Hoffar, J. F.“Calculating Construction Damages”, John Wiley & Sons,1992
24.“Forensic Schedule Analysis”, AACE Intertional Recommended Practice, No.29R-03, 2011.
25.Hughes, G. A. and Barber, J. N., “Building and CivilEngineering Claims in Perspective”, Longman Scientific& Technical, London, 1993
26.Conlon, E.“Compensation of Delay under the New Irish Public Sector Works Contracts”, Journal of the Institution of Civil Engineering Surveyors,U.K., 2007.
27.Aibinu, A. A., “Avoiding and Mitigating Delay and Disruption Claims Conflict: Role of Precontract Negotiation”, Journal of Legal Affairs and Dispute Resolution in Engineering and Construction, ASCE, 2009.
28.Braimah, N., “An Investigation into the Use of Construction Delay and Disruption Analysis Methodologies”, Ph. D. Dissertation, University of Wolverhampton, U.K., 2008.
29.Anderson, O. C., and Gentilcore E. B., “A View from the Ground Up: Calculating Damages due to Construction Project Delay” , American Bar Association, 2005.
30.Ibbs, W., Nguyen, L.D. and Simonian, L., “Concurrent Delays and Apportionment of Damages”, Journal of Construction Engineering and Management, ASCE, 2010.
31.McGreevy, S. L., “When You See a Claim Coming, Prepare”, Contractor Magazine, Vol 5, No.11, 2004.
32.Zack, J., “Calculation and Recovery of Home Office Overhead”, International Cost Engineering Council, Australia, 2002.
33.Cilensek, R., “Understanding Contractor Overhead”, Cost Engineering, Vol.33, No.12, pp.21-23, 1991.
34.Michener, L., “The Traps and Pitfalls of Construction Delay Claims in Ontario”, Glenn Grenier,Canada, 2005.
35.McCaleb, S., “Federal Circuit Expands Contractor Recovery of Unabsorbed Overhead”, Procurement Law Advisor, Vol.6, No.6, 2003.
36.Loulakis, M. and Santiago, S., “Follow the Formula” Civil Engineering, Vol.69, No.7, 1999.
37.Warshawsky, B., “Unabsorbed Overhead:Meaning and Method” Cost Engineering, Vol.39, No.10, , 1997.
38.Markis, P. E., “Eichleay Update” AACE International Transactions”, September 17, Morgantown, 2004.
39.Anderson, G.A., “Delay Damages: Recovery in New York Differs”, GBC Associate’s Corner, USA, 2004.
40.Singh, A., and Taam, T., “Unabsorbed Overhead: Eichleay and Other Methods”, Construction Research Congress, ASCE, 2009.
41.Rubin, R. A., Guy, S. D., Maevis, A. C., and Fairweather, V., “Delay Analysis Construction Claim Analysis, Presentation, Defense”, Van Nostrand Reinhold, New York, 1983.
42.Alkass, S., Mazerolle, M. and Harris, F., “Construction Delay Analysis Techniques”, Construction Management and Economics, 1996.
43.Bramble, B. B., and Callahan, M. T., “Construction Delay Claims”, Aspen Law & Business, Gaithersburg, 2000.
44.Schumacher, L., “Quantifying and Apportioning Delay on Construction Projects”, Cost Engineering, 37(2), 1995.
45.Lovejoy, V. A., “Claims Schedule Development and Analysis: Collapsed As-Built Scheduling for Beginners”, Cost Engineering, Vol. 46, No. 1, pp.27-30, 2004.
46.Sgarlata, M. A., Brasco, C. J., “Successful Claims Resolution through an Understanding of the Law Governing Allocation of Risk for Delay and Disruption”, Construction Management Association of America, 2004.
47.Ostrowski, V. M. and Midgette, M. T., “Concurrent Delay Analysis in Litigation”, Cost Engineering Vol. 48, No. 1, 2006.
48.Ndekugri, I., Braimah, N. and Gameson R.,“Delay Analysis within Construction Contracting Organizations”, Journal of Professional Issues in Engineering Education and Practice, ASCE, 2008.
49.Braimah, N., “An Investigation into the Use of Construction Delay and Disruption Analysis Methodologies”, Ph. D. Dissertation, University of Wolverhampton, 2008.
50.Zhang, K. and Hegazy, T., “Apportioning Concurrent Delays and Accelerations Using Daily Windows”, Construction Research Congress, ASCE, 2005.
51.Ibbs, W., Nguyen, L. D. and Simonian, L., “Concurrent Delay and Apportionment of Damages”, Journal of Construction Engineering and Management, ASCE, 2010.
52.Scott, S. and Harris, R. A., “United Kingdom Construction Claims: Views of Professtionals” Journal of Construction Engineering and Management, ASCE, 2004.
53.Ibbs, W. and Nguyen, L. D., “Alternative for Quantifying Field-Overhead Damages” Journal of Construction Engineering and Management, ASCE, 2007.
54.Rider, R. J. and Long, R. J, “Analysis of Concurrent / Pacing Delay”, Long International, Inc, 2010.
55.Kao, C. K. and Yang, J. B., “Comparison of Windows-Based Delay Analysis Methods”, International Journal of Project Management, Science Direct, 2009.
56.Kraiem, Z. M. and Diekmann J. E., “Concurrent Delays in Construction Projects”, Journal of Construction Engineering and Management, ASCE, 1987.
57.Lo, T. Y., Fung, I. W. H. and Tung, K. C. F., “Construction Delays in Hong Kong Civil Engineering Projects”, Journal of Construction Engineering and Management, ASCE, 2006.
58.Menesi, W., “Construction Scheduling Using Critical Path Analysis with Separate Time Segments”, University of Waterloo.